TERMS & CONDITIONS OF USE

1. Acceptance of Terms

Welcome to Electryfy.com (the “Website”), owned and operated by Lighting of Tomorrow, LLC, a Florida limited liability company doing business as Electryfy and Lighting of Tomorrow (collectively referred to herein as “Company,” “Seller,” “we,” “us,” or “our”).

By accessing, browsing, submitting forms, requesting services, purchasing products, or otherwise using this Website, you (“User,” “Buyer,” or “Customer”) acknowledge that you have read, understood, and agree to be legally bound by these Terms and Conditions, as well as any additional agreements referenced herein, including but not limited to:

• Sales & Services Agreement
• Return & Exchange Policy
• Privacy Policy

If you do not agree to these Terms, you must not use this Website.

2. Business Structure and Use of Trade Names

Lighting of Tomorrow, LLC operates under the following registered DBAs:

• Electryfy – used for electrical contracting, EV charger installations, lighting services, engineering, and project execution
• Lighting of Tomorrow – used for product sales including lighting fixtures, EV chargers, poles, and replacement components

User acknowledges that purchases, contracts, invoices, or communications may be issued under either name, and all such transactions are legally binding under the same entity.

3. Scope of Services and Products

The Website provides:

• Electrical contracting services
• Lighting retrofits and installations
• EV charger installation services
• Engineering and permitting support
• Sale of lighting, electrical, and EV charging products

All services are subject to separate written proposals, estimates, or agreements. Website content does not constitute a binding offer.

4. Estimates, Quotes, and Project Work

All estimates provided through the Website or otherwise are:

• Valid for a limited time as stated in the proposal
• Subject to change based on site conditions, permitting, material costs, or scope changes
• Non-binding until accepted in writing

Project-based work may require:

• Deposits
• Signed agreements
• Approved drawings or engineering

User agrees that field conditions, code requirements, or unforeseen circumstances may result in change orders and additional costs.

5. Orders and Product Purchases

All product orders placed through the Website are subject to:

• Availability of inventory
• Supplier and manufacturer fulfillment timelines
• Pricing verification

Seller reserves the right to:

• Cancel or refuse any order
• Adjust pricing due to errors or market fluctuations
• Limit quantities

Title and risk of loss pass to Buyer upon shipment.

6. Payment Terms

Unless otherwise agreed in writing:

• All invoices are due upon receipt
• Past due balances beyond 30 days incur a 1.5% monthly finance charge (18% APR)
• Buyer agrees that late fees are enforceable and will accrue until paid

Failure to pay may result in:

• Suspension of services
• Order cancellation
• Legal action or collections
• Filing of a construction lien under Florida law

7. Returns, Refunds, and Exchanges

All product returns are governed by our Return & Exchange Policy, which includes but is not limited to:

• 30-day return window
• Mandatory 25% restocking fee
• Buyer-paid return shipping
• RMA requirement

Certain items are non-returnable, including custom or installed products.

8. Warranties

A. Workmanship Warranty (Services)

All electrical services performed by Company include a one (1) year workmanship warranty from the date of completion in accordance with Florida law.

B. Product Warranty (Manufacturer)

Products sold may carry manufacturer warranties that vary by brand and model. Company does not guarantee uniform warranty terms and is not responsible for manufacturer warranty limitations.

9. Licensing and Compliance

Company operates under Florida Electrical Contractor License EC13014730 and performs work in compliance with:

• Florida Building Code (FBC)
• National Electrical Code (NEC)
• Applicable municipal requirements

User agrees that permitting, inspections, and approvals may impact project timelines.

10. User Conduct

User agrees not to:

• Use the Website for unlawful purposes
• Submit false or misleading information
• Attempt to disrupt or compromise Website security
• Copy, reproduce, or exploit Website content without permission

11. Intellectual Property

All Website content, including text, images, graphics, logos, and designs, are the property of Company and protected under applicable intellectual property laws.

No content may be used, reproduced, or distributed without prior written consent.

12. Limitation of Liability

TO THE MAXIMUM EXTENT PERMITTED BY LAW:

• Company’s liability shall not exceed the amount paid for the applicable product or service
• Company shall not be liable for indirect, incidental, or consequential damages, including loss of business, revenue, or data

13. Third-Party Products and Services

Company may provide or install products manufactured by third parties. Company is not responsible for:

• Manufacturer defects
• Delays in supply chain
• Changes in product specifications

14. Force Majeure

Company shall not be liable for delays or failure to perform due to causes beyond its control, including but not limited to:

• Weather events
• Supply chain disruptions
• Labor shortages
• Government actions
• Utility delays

15. Construction Lien Notice

NOTICE TO OWNER: Failure to pay for services or materials may result in a construction lien against the property pursuant to Florida Statutes Chapter 713.

16. Dispute Resolution

Any dispute arising out of or related to these Terms shall be resolved by:

• Binding arbitration in Broward or Miami-Dade County, Florida
• In accordance with the American Arbitration Association rules

Judgment may be entered in any court of competent jurisdiction.

17. Governing Law

These Terms shall be governed by the laws of the State of Florida. Venue shall be exclusively in Broward County, Florida.

18. Attorney’s Fees

In any dispute or enforcement action, the prevailing party shall be entitled to recover reasonable attorney’s fees and costs.

19. Modifications to Terms

Company reserves the right to update or modify these Terms at any time. Continued use of the Website constitutes acceptance of the updated Terms.

20. Electronic Communications

User consents to receive communications electronically, including:

• Emails
• Quotes
• Invoices
• Notices

Such communications satisfy any legal requirement for written notice.

21. Entire Agreement

These Terms, together with referenced policies and agreements, constitute the entire agreement between the parties and supersede all prior communications.

22. Contact Information

Lighting of Tomorrow, LLC d/b/a Electryfy

📍 1076 NW 53rd St, Fort Lauderdale, FL 33309

📞 954-626-0267

📧 info@electryfy.com

🌐 www.electryfy.com

Acknowledgment

By using this Website, submitting information, requesting services, or purchasing products, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions.